Owner Affidavit of Completion
Basic Information
Date:
Owner:
Owner’s Mailing Address:
Original Contractor:
Original Contractor’s Mailing Address:
Property: [include legal description]
Improvements:
Completion Date: [date]
Affiant, [name of affiant], on oath swears that the following statements are true and within the personal knowledge of Affiant:
1.Date of Completion. The Improvements to the Property were completed on the Completion Date. For purposes of this affidavit, “completion” means the actual completion of the work, including any extras or change orders reasonably required or contemplated under the original contract, other than warranty or repair work.
|
For original contracts entered into before January 1, 2022, include the following. |
2.Claims against Retained Funds. No subcontractor or other lien claimant may have a lien on retained funds unless the claimant files an affidavit claiming a lien no later than the fortieth day after the work under the original contract is completed.
|
For original contracts entered into on or after January 1, 2022, include the following. |
2.Claims against Retained Funds. No subcontractor or other lien claimant may have a lien on retained funds unless the claimant files an affidavit claiming a lien in the time and manner required by chapter 53 of the texas property code.
|
Continue with the following. |
3.Statement as to Other Notices. Owner states that Owner has received a written request to receive a copy of an affidavit of completion from the following persons who have furnished labor or materials for the Property and from no other persons:
Persons requesting copy of affidavit of completion: [list].
[Name of owner]
SUBSCRIBED AND SWORN TO before me on __________________ by [name of affiant].
Notary Public, State of Texas